Accurate
Country-specific legal content
Drafted with legal expertise for each jurisdiction, far more thorough than AI-generated drafts that copy generic clauses across borders.
Legal & BusinessUnited States
Free Construction Contract Template
Draft a comprehensive construction contract for residential or commercial projects. Cover scope of work, payment schedules, timelines, warranties, and legal protections with our professional US template.
Free to useInstant PDFNo account required
PDF (free) + editable Word (.docx) with Expert
CONSTRUCTION CONTRACT
Primary Residence Renovation - 175,000.00 USD - Fixed Price
PROPERTY OWNER
Westbrook Family Trust
1450 Hillside Terrace, Scottsdale, AZ 85251
By: (480) 555-0312, westbrook.trust@email.com
CONTRACTOR
Horizon Builders Inc.
Contact: Thomas Grant
8200 E Camelback Road, Suite 120, Scottsdale, AZ 85251
(480) 555-0198
info@horizonbuilders.com
License: ROC-287456
Insurance: GL-2026-445591
8200 E Camelback Road, Suite 120, Scottsdale, AZ 85251
(480) 555-0198
info@horizonbuilders.com
License: ROC-287456
Insurance: GL-2026-445591
By: Thomas Grant, License: ROC-287456
Project: Primary Residence Renovation / Fixed Price
Amount: 175,000.00 USD | Start: March 26, 2026
This Construction Contract ("Contract") is entered into as of March 26, 2026 by and between:
Westbrook Family Trust, with an address at 1450 Hillside Terrace, Scottsdale, AZ 85251 ("Owner"), and
Horizon Builders Inc., with an address at 8200 E Camelback Road, Suite 120, Scottsdale, AZ 85251, License No. ROC-287456 ("Contractor").
Owner and Contractor may be referred to individually as a "Party" and collectively as the "Parties."
Westbrook Family Trust, with an address at 1450 Hillside Terrace, Scottsdale, AZ 85251 ("Owner"), and
Horizon Builders Inc., with an address at 8200 E Camelback Road, Suite 120, Scottsdale, AZ 85251, License No. ROC-287456 ("Contractor").
Owner and Contractor may be referred to individually as a "Party" and collectively as the "Parties."
1.
SCOPE OF WORK
Contractor agrees to furnish all labor, materials, equipment, and services necessary to complete the following construction project:
Project: Primary Residence Renovation
Location: 1450 Hillside Terrace, Scottsdale, AZ 85251
Type: New Construction
Description of Work: Complete interior renovation including kitchen and master bath remodel, flooring replacement, electrical upgrade to 200-amp panel, plumbing fixture replacement, interior painting, and custom cabinetry installation.
Plans and Specifications: The work shall be performed in accordance with Architectural plans by Desert Design Studio, dated February 15, 2026, Revision B, which are incorporated herein by reference.
Contractor shall perform all work in a good and workmanlike manner, in compliance with all applicable building codes, regulations, and industry standards. Consistent with the Spearin doctrine (United States v. Spearin, 248 U.S. 132 (1918)), Owner warrants the adequacy of the plans and specifications furnished by Owner, and Contractor shall not be responsible for defects arising from Owner-furnished plans if the work is performed in accordance with them. All materials shall be new and of good quality unless otherwise specified.
Project: Primary Residence Renovation
Location: 1450 Hillside Terrace, Scottsdale, AZ 85251
Type: New Construction
Description of Work: Complete interior renovation including kitchen and master bath remodel, flooring replacement, electrical upgrade to 200-amp panel, plumbing fixture replacement, interior painting, and custom cabinetry installation.
Plans and Specifications: The work shall be performed in accordance with Architectural plans by Desert Design Studio, dated February 15, 2026, Revision B, which are incorporated herein by reference.
Contractor shall perform all work in a good and workmanlike manner, in compliance with all applicable building codes, regulations, and industry standards. Consistent with the Spearin doctrine (United States v. Spearin, 248 U.S. 132 (1918)), Owner warrants the adequacy of the plans and specifications furnished by Owner, and Contractor shall not be responsible for defects arising from Owner-furnished plans if the work is performed in accordance with them. All materials shall be new and of good quality unless otherwise specified.
2.
CONTRACT PRICE
Owner agrees to pay Contractor for the performance of the work described herein as follows:
Fixed Price: The total contract price for all work described in this Contract is 175,000.00 USD. This price includes all labor, materials, equipment, overhead, and profit.
Fixed Price: The total contract price for all work described in this Contract is 175,000.00 USD. This price includes all labor, materials, equipment, overhead, and profit.
3.
PAYMENT SCHEDULE
Payment Schedule: Monthly progress payments.
Deposit: Owner shall pay a deposit of 17,500.00 USD upon execution of this Contract. The deposit shall be applied toward the contract price.
Retainage: Owner shall withhold 10% of each progress payment as retainage. Retainage shall be released within thirty (30) days after substantial completion, final inspection, and receipt of all required lien waivers.
Final Payment: Final payment due within 30 days of substantial completion, final inspection approval, and receipt of all unconditional lien waivers.
Late payments shall accrue interest at a rate of 1.5% per month or the maximum rate permitted by applicable law, whichever is less. Payments made under this Contract shall comply with any applicable state prompt-payment statute (e.g., Cal. Bus. and Prof. Code §7108.5; Fla. Stat. §§218.70-.79; Tex. Gov't Code §§2251.021 et seq.; NY Gen. Bus. Law §756). For federally funded projects, payments to subcontractors and suppliers shall comply with the Miller Act, 40 U.S.C. §§3131-3134, and applicable state Little Miller Act analogs.
Deposit: Owner shall pay a deposit of 17,500.00 USD upon execution of this Contract. The deposit shall be applied toward the contract price.
Retainage: Owner shall withhold 10% of each progress payment as retainage. Retainage shall be released within thirty (30) days after substantial completion, final inspection, and receipt of all required lien waivers.
Final Payment: Final payment due within 30 days of substantial completion, final inspection approval, and receipt of all unconditional lien waivers.
Late payments shall accrue interest at a rate of 1.5% per month or the maximum rate permitted by applicable law, whichever is less. Payments made under this Contract shall comply with any applicable state prompt-payment statute (e.g., Cal. Bus. and Prof. Code §7108.5; Fla. Stat. §§218.70-.79; Tex. Gov't Code §§2251.021 et seq.; NY Gen. Bus. Law §756). For federally funded projects, payments to subcontractors and suppliers shall comply with the Miller Act, 40 U.S.C. §§3131-3134, and applicable state Little Miller Act analogs.
4.
RETAINAGE
Owner shall retain 10% of each progress payment as retainage to ensure satisfactory completion of the work. The total retainage amount shall be released to Contractor under the following conditions:
a) The work has reached substantial completion as defined in this Contract
b) All required inspections have been passed and certificates of occupancy or completion obtained (if applicable)
c) Contractor has provided unconditional lien waivers from all subcontractors and suppliers
d) All punch list items have been completed to Owner's reasonable satisfaction
e) Contractor has provided all warranties, manuals, and as-built drawings
a) The work has reached substantial completion as defined in this Contract
b) All required inspections have been passed and certificates of occupancy or completion obtained (if applicable)
c) Contractor has provided unconditional lien waivers from all subcontractors and suppliers
d) All punch list items have been completed to Owner's reasonable satisfaction
e) Contractor has provided all warranties, manuals, and as-built drawings
5.
PROJECT TIMELINE
Contractor shall commence the work on or before March 26, 2026 and shall achieve substantial completion on or before July 16, 2026.
Substantial Completion: The stage when all major construction work is complete, the residence is safe for occupancy, and only minor punch list items remain.
Time is of the essence in this Contract. Contractor shall prosecute the work diligently and shall notify Owner promptly of any circumstances that may delay the scheduled completion.
Substantial Completion: The stage when all major construction work is complete, the residence is safe for occupancy, and only minor punch list items remain.
Time is of the essence in this Contract. Contractor shall prosecute the work diligently and shall notify Owner promptly of any circumstances that may delay the scheduled completion.
6.
FORCE MAJEURE
Neither Party shall be liable for delays or failures in performance resulting from causes beyond its reasonable control, including but not limited to:
a) Acts of God (earthquakes, floods, hurricanes, tornadoes)
b) Fire or explosion
c) War, terrorism, or civil unrest
d) Government actions, embargoes, or sanctions
e) Epidemics or pandemics
f) Strikes or labor disputes (not involving Contractor's own employees)
The affected Party shall provide written notice within five (5) business days of the force majeure event and shall use commercially reasonable efforts to mitigate the delay. The completion date shall be extended by the duration of the force majeure event.
a) Acts of God (earthquakes, floods, hurricanes, tornadoes)
b) Fire or explosion
c) War, terrorism, or civil unrest
d) Government actions, embargoes, or sanctions
e) Epidemics or pandemics
f) Strikes or labor disputes (not involving Contractor's own employees)
The affected Party shall provide written notice within five (5) business days of the force majeure event and shall use commercially reasonable efforts to mitigate the delay. The completion date shall be extended by the duration of the force majeure event.
7.
WEATHER DAYS
Contractor is allowed up to 10 weather days during the project duration. A weather day is defined as any day on which weather conditions prevent work from being performed safely or would compromise the quality of the work. Contractor shall document all claimed weather days in the daily construction log. Weather days beyond the allowance shall extend the completion date on a day-for-day basis, provided Contractor has given timely written notice to Owner.
8.
CHANGE ORDERS
Change Order Process: Written change orders only.
No changes to the scope, schedule, or price of the work shall be made except by written change order signed by both Parties, consistent with customary AIA Document A201 General Conditions Article 7 change-order practice. All change orders shall describe the proposed change in detail, including the effect on the contract price and completion date.
Contractor shall not proceed with any changed work until the change order has been approved by Owner.
Markup: Change order work shall be priced at cost plus a 15% markup for overhead and profit.
No changes to the scope, schedule, or price of the work shall be made except by written change order signed by both Parties, consistent with customary AIA Document A201 General Conditions Article 7 change-order practice. All change orders shall describe the proposed change in detail, including the effect on the contract price and completion date.
Contractor shall not proceed with any changed work until the change order has been approved by Owner.
Markup: Change order work shall be priced at cost plus a 15% markup for overhead and profit.
9.
WARRANTIES
Warranty Period: Two (2) years from the date of substantial completion.
Warranty Scope: Contractor warrants that Materials and workmanship shall be free from defects for the warranty period specified above.
If any defect is discovered during the warranty period, Contractor shall, at Contractor's sole expense, repair or replace the defective work within a reasonable time after receiving written notice from Owner. Owner must notify Contractor of any defect within 60 days of discovering the defect.
Manufacturer Warranties: In addition to the Contractor's warranty, the following manufacturer warranties apply:
Roofing materials - 25 year manufacturer warranty
HVAC system - 10 year parts and compressor warranty
Windows - 20 year limited manufacturer warranty
Appliances - Standard manufacturer warranty
This warranty does not cover damage caused by Owner's misuse, neglect, failure to maintain, unauthorized modifications, or normal wear and tear.
Warranty Scope: Contractor warrants that Materials and workmanship shall be free from defects for the warranty period specified above.
If any defect is discovered during the warranty period, Contractor shall, at Contractor's sole expense, repair or replace the defective work within a reasonable time after receiving written notice from Owner. Owner must notify Contractor of any defect within 60 days of discovering the defect.
Manufacturer Warranties: In addition to the Contractor's warranty, the following manufacturer warranties apply:
Roofing materials - 25 year manufacturer warranty
HVAC system - 10 year parts and compressor warranty
Windows - 20 year limited manufacturer warranty
Appliances - Standard manufacturer warranty
This warranty does not cover damage caused by Owner's misuse, neglect, failure to maintain, unauthorized modifications, or normal wear and tear.
10.
INSURANCE REQUIREMENTS
General Liability Insurance: Contractor shall maintain commercial general liability insurance with minimum coverage of 1,000,000.00 USD per occurrence and 2,000,000.00 USD aggregate. Contractor shall name Owner as an additional insured on the general liability policy.
Workers' Compensation: Contractor shall maintain workers' compensation insurance as required by the laws of the State of Arizona covering all of Contractor's employees engaged in the work. Contractor shall provide Owner with a certificate of insurance prior to commencing work. Any indemnification obligation of Contractor under this Contract shall be construed and enforced consistent with applicable state anti-indemnity statutes (e.g., Cal. Civ. Code §2782; N.Y. Gen. Oblig. Law §5-322.1; Tex. Ins. Code §§151.101-.151).
Builder's Risk Insurance: Contractor shall obtain and maintain builder's risk insurance covering the full value of the work during the construction period, protecting against loss or damage from fire, theft, vandalism, and other covered perils.
All insurance policies required under this Contract shall be maintained from the date work commences until final completion and acceptance. Contractor shall provide certificates of insurance to Owner upon request and shall provide thirty (30) days' advance written notice of any cancellation or material change in coverage.
Workers' Compensation: Contractor shall maintain workers' compensation insurance as required by the laws of the State of Arizona covering all of Contractor's employees engaged in the work. Contractor shall provide Owner with a certificate of insurance prior to commencing work. Any indemnification obligation of Contractor under this Contract shall be construed and enforced consistent with applicable state anti-indemnity statutes (e.g., Cal. Civ. Code §2782; N.Y. Gen. Oblig. Law §5-322.1; Tex. Ins. Code §§151.101-.151).
Builder's Risk Insurance: Contractor shall obtain and maintain builder's risk insurance covering the full value of the work during the construction period, protecting against loss or damage from fire, theft, vandalism, and other covered perils.
All insurance policies required under this Contract shall be maintained from the date work commences until final completion and acceptance. Contractor shall provide certificates of insurance to Owner upon request and shall provide thirty (30) days' advance written notice of any cancellation or material change in coverage.
11.
PERMITS AND COMPLIANCE
Permits and Approvals: Contractor shall be responsible for obtaining all necessary building permits, licenses, and approvals required for the performance of the work. Contractor represents and warrants that it holds a valid contractor's license in the jurisdiction where the work is performed as required by applicable state contractor-licensing law (e.g., Cal. Bus. and Prof. Code §§7000-7145.5 (CSLB); Fla. Stat. ch. 489; Tex. Occ. Code chs. 1301-1302; N.Y. Gen. Bus. Law §770) and shall maintain such license in good standing throughout the term of this Contract.
Building Codes: Contractor shall be responsible for ensuring all work complies with applicable building codes, zoning regulations, and local ordinances. Contractor shall schedule and coordinate all required inspections with the appropriate building authorities.
Building Codes: Contractor shall be responsible for ensuring all work complies with applicable building codes, zoning regulations, and local ordinances. Contractor shall schedule and coordinate all required inspections with the appropriate building authorities.
12.
OSHA COMPLIANCE
Contractor shall comply with all applicable Occupational Safety and Health Administration (OSHA) standards and regulations, including the Construction Industry Safety and Health Standards set forth at 29 C.F.R. Part 1926, and the Occupational Safety and Health Act of 1970, 29 U.S.C. §§651 et seq. Contractor shall maintain a safe work environment at all times and shall implement and enforce all required safety measures, including but not limited to:
a) Fall protection for work at heights above six (6) feet
b) Proper scaffolding and ladder safety
c) Personal protective equipment (PPE) for all workers
d) Hazard communication and safety data sheets for all chemicals
e) Electrical safety and lockout/tagout procedures
f) Trenching and excavation safety
Contractor shall designate a competent person responsible for site safety and shall maintain all required safety records and documentation.
a) Fall protection for work at heights above six (6) feet
b) Proper scaffolding and ladder safety
c) Personal protective equipment (PPE) for all workers
d) Hazard communication and safety data sheets for all chemicals
e) Electrical safety and lockout/tagout procedures
f) Trenching and excavation safety
Contractor shall designate a competent person responsible for site safety and shall maintain all required safety records and documentation.
13.
ENVIRONMENTAL COMPLIANCE
Contractor shall comply with all applicable federal, state, and local environmental laws and regulations, including but not limited to:
a) Proper handling, storage, and disposal of construction waste and debris
b) Stormwater management and erosion control measures
c) Lead paint and asbestos abatement protocols (for renovation of structures built before 1978)
d) Dust and noise control measures
e) Protection of trees, wetlands, and other environmental features as required
If hazardous materials are discovered during construction, Contractor shall immediately stop work in the affected area, secure the area, and notify Owner. The cost of hazardous material remediation shall be the responsibility of Owner unless caused by Contractor's actions.
a) Proper handling, storage, and disposal of construction waste and debris
b) Stormwater management and erosion control measures
c) Lead paint and asbestos abatement protocols (for renovation of structures built before 1978)
d) Dust and noise control measures
e) Protection of trees, wetlands, and other environmental features as required
If hazardous materials are discovered during construction, Contractor shall immediately stop work in the affected area, secure the area, and notify Owner. The cost of hazardous material remediation shall be the responsibility of Owner unless caused by Contractor's actions.
14.
DISPUTE RESOLUTION
Dispute Resolution: Any dispute, controversy, or claim arising out of or relating to this Contract shall be resolved by Mediation, followed by arbitration if unresolved. The Parties agree to first attempt to resolve any dispute through good-faith mediation with a mediator experienced in construction disputes. If mediation is unsuccessful within thirty (30) days, the dispute shall be resolved through binding arbitration in accordance with the Construction Industry Arbitration Rules of the American Arbitration Association.
Pending resolution of any dispute, Contractor shall continue to perform the work diligently unless otherwise directed by Owner or unless the dispute relates to safety concerns.
Pending resolution of any dispute, Contractor shall continue to perform the work diligently unless otherwise directed by Owner or unless the dispute relates to safety concerns.
15.
LIEN WAIVERS
Contractor shall provide Owner with conditional lien waivers from Contractor, all subcontractors, and all material suppliers with each progress payment request, and unconditional lien waivers upon receipt of each progress payment, in the form and manner required by applicable state mechanic's-lien law (e.g., Cal. Civ. Code §§8400-8494; Fla. Stat. §§713.001-.37; Tex. Prop. Code ch. 53; N.Y. Lien Law §§1 et seq.).
Final payment shall not be due until Contractor has provided unconditional final lien waivers from Contractor, all subcontractors, and all material suppliers for the full amount of the contract price, including all change orders. Owner may withhold sufficient funds to cover any unresolved lien claims or potential lien claims.
Final payment shall not be due until Contractor has provided unconditional final lien waivers from Contractor, all subcontractors, and all material suppliers for the full amount of the contract price, including all change orders. Owner may withhold sufficient funds to cover any unresolved lien claims or potential lien claims.
16.
TERMINATION
Termination for Cause: Either Party may terminate this Contract if the other Party materially breaches any provision and fails to cure such breach within ten (10) days of receiving written notice thereof. Without limitation, the following constitute grounds for termination for cause: (a) Contractor abandons the work for more than fourteen (14) consecutive days; (b) Contractor fails to maintain required insurance; (c) Contractor fails to pay subcontractors or suppliers; (d) Contractor repeatedly fails to comply with applicable codes or safety requirements; (e) either Party becomes insolvent or files for bankruptcy.
Termination for Convenience: Owner may terminate this Contract for any reason upon thirty (30) days' written notice to Contractor. In the event of termination for convenience, Contractor shall be compensated for all work satisfactorily performed and materials purchased for the project through the date of termination, plus a reasonable amount for demobilization costs.
Suspension: Owner may suspend the work at any time upon seven (7) days' written notice to Contractor. During any suspension, Contractor shall secure the work site and protect all completed work. If the suspension exceeds thirty (30) days, Contractor may request an equitable adjustment to the contract price and completion date.
Termination for Convenience: Owner may terminate this Contract for any reason upon thirty (30) days' written notice to Contractor. In the event of termination for convenience, Contractor shall be compensated for all work satisfactorily performed and materials purchased for the project through the date of termination, plus a reasonable amount for demobilization costs.
Suspension: Owner may suspend the work at any time upon seven (7) days' written notice to Contractor. During any suspension, Contractor shall secure the work site and protect all completed work. If the suspension exceeds thirty (30) days, Contractor may request an equitable adjustment to the contract price and completion date.
17.
GOVERNING LAW
This Contract shall be governed by and construed in accordance with the laws of the State of Arizona, without regard to its conflict of laws principles. Any legal action or proceeding arising under this Contract shall be brought exclusively in the courts located in the State of Arizona, and the Parties hereby consent to personal jurisdiction and venue therein.
18.
ENTIRE AGREEMENT
This Contract, together with all exhibits, schedules, and change orders, constitutes the entire agreement between the Parties with respect to the construction project described herein and supersedes all prior and contemporaneous agreements, understandings, negotiations, and discussions, whether oral or written. No amendment or modification of this Contract shall be valid unless made in writing and signed by both Parties. If any provision of this Contract is held to be invalid or unenforceable, the remaining provisions shall continue in full force and effect.
IN WITNESS WHEREOF, the parties have executed this Agreement as of the date indicated.
PROPERTY OWNER
Westbrook Family Trust
Date: ____________________
CONTRACTOR
Horizon Builders Inc.
Date: ____________________
Available as a print-ready PDF or an editable Microsoft Word (.docx) file.
What Is a Construction Contract?
A construction contract is a legally binding agreement between a property owner and a contractor that defines the terms for a building project. It covers everything from the scope of work and materials to payment schedules, timelines, warranties, and dispute resolution procedures. Whether the project is a new home, a commercial renovation, or a simple repair, a written contract is essential to protect both parties.
Construction contracts are used across residential and commercial projects to ensure that all parties understand their responsibilities before work begins. They establish clear expectations for quality, cost, and timeline while providing legal recourse if either side fails to perform. In most US states, contractors are legally required to provide a written contract for projects above a certain dollar threshold.
A well-drafted construction contract reduces the risk of disputes, cost overruns, and project delays. It addresses common issues like change orders, payment retainage, insurance requirements, and permit responsibilities. Both the property owner and the contractor benefit from having these terms documented in writing before the first shovel hits the ground.
What's Covered in This Template
Doxuno's construction contract template includes all the essential sections needed to create a comprehensive agreement for any building project. Each section can be customized to fit residential or commercial construction needs.
Property Owner Information
Contractor Details
Scope of Work
Contract Price and Payment
Timeline and Schedule
Change Order Process
Warranties
Insurance Requirements
Permits and Compliance
Dispute Resolution
Termination Clauses
Signatures and Execution
How to Create a Construction Contract
Creating a solid construction contract protects both the property owner and the contractor throughout the building process. Our template guides you through each section so nothing is overlooked. Follow these five steps to build your agreement.
- 1
Identify the Parties
Enter the full legal names, addresses, phone numbers, and emails for both the property owner and the contractor. Include the contractor's state license number and insurance policy number so both parties are clearly identified and verifiable before work begins.
- 2
Define the Scope of Work
Describe the project in detail: the type of work (new construction, renovation, addition, repair, demolition, or landscaping), the site address, a thorough description of what will be built or modified, the materials to be used, and any referenced architectural plans or specifications.
- 3
Set the Price and Payment Terms
Choose the contract type (fixed price, cost plus, time and materials, or unit price) and enter the total amount. Specify the deposit or down payment, retainage percentage (typically 5-10%), and select a payment schedule: monthly progress, milestone based, draw schedule, or upon completion.
- 4
Establish the Timeline
Set the project start date and estimated completion date. Define what constitutes substantial completion and decide whether to include liquidated damages for delays (a daily or weekly penalty). Address force majeure events like natural disasters or government orders that could excuse delays beyond either party's control.
- 5
Add Warranties and Legal Protections
Specify the warranty period for workmanship and materials, define the change order process, set insurance requirements, assign permit responsibilities, and choose a dispute resolution method (mediation, arbitration, or litigation). Select the governing state law and review everything before signing.
Why Doxuno documents are different
Four things that make our templates more thorough than AI-generated drafts and more current than static template libraries.
Always current
Always current with the law
Templates carrying statute references are continuously updated as the law changes. Your document always reflects the current legal framework.
Free PDF
Print-ready PDF
Free to download. Vector text, embedded fonts, statute citations baked in. Print, sign, file. Ready for any signing flow including electronic signature.
Word · .docx
Editable Word (.docx)
Continue editing in Word after download. Add custom clauses, reuse the template for similar agreements, or share with a colleague for collaborative review.
Requires Expert one-time unlock or any paid Doxuno subscription.
Legal Considerations for US Construction Contracts
Construction contracts in the United States are governed by a combination of state contract law, building codes, and industry-specific regulations. Understanding the legal landscape helps both property owners and contractors protect their interests and avoid common pitfalls that lead to disputes and litigation.
This template is provided for informational purposes and does not constitute legal advice. For large or complex construction projects, consult a licensed attorney in your state who specializes in construction law.
Reviewed by legal professionals. The content on this page and the template clauses have been reviewed by licensed attorneys in the United States to ensure accuracy and legal soundness for standard construction contract scenarios.
Contractor Licensing Requirements
Most US states require contractors to hold a valid license for construction work above a certain dollar threshold. Working with an unlicensed contractor can void your contract, eliminate your ability to enforce warranties, and leave you without legal recourse if problems arise. Always verify a contractor's license status with your state's licensing board before signing the agreement.
Mechanic's Lien Rights
Under US law, contractors, subcontractors, and material suppliers have the right to file a mechanic's lien against a property if they are not paid for their work or materials. Lien laws vary significantly by state, but they generally require the claimant to file within a specific timeframe after completing work. Property owners can protect themselves by requiring lien waivers with each progress payment and by using a joint-check arrangement for subcontractors.
Retainage and Final Payment
Retainage (typically 5-10% of each progress payment) is a standard practice in the construction industry that protects the property owner by holding back a portion of payment until the project reaches substantial completion. Many states regulate the maximum retainage percentage and the timeline for releasing retained funds. The contract should clearly state the retainage rate, conditions for release, and the process for final inspection and acceptance.
Frequently Asked Questions
Build with Confidence
Create a professional U.S. construction contract in minutes. Our American template covers scope of work, payment terms, timelines, warranties, and everything you need to protect your building project in the United States.
Free PDF · Editable Word with Expert · No account required